Matches in SemOpenAlex for { <https://semopenalex.org/work/W87378054> ?p ?o ?g. }
Showing items 1 to 77 of
77
with 100 items per page.
- W87378054 abstract "Time is an extremely important issue in construction. Timely completion of the construction works by the contractor is of great importance to the employer. Therefore, most construction contracts specify time for performance in achieving completion of the works. However, during the execution of the contract, circumstances may arise which render that completion date unenforceable. At common law, the contractor’s obligation to complete the works by the specified date is removed if the employer delays the contractor in the execution of the works. When the specified completion date no longer applies, time is said to be “at large�, and the contractor’s obligation is merely to complete the works within a reasonable time. What does it mean by reasonable time? It is most certainly not “as and when the contractor sees fit�. The study is aimed at determining the meaning of “reasonable time� when time is at large. Findings of this study will assist contractors to assess a reasonable time to complete the works when time at large occurs. The approach adopted in this research is case law based. There are no limitations as for the court cases referred to in this study in terms of type of projects as long as the case is related to reasonable time. A total of ten cases centered on what is a reasonable time were studied. Through the analysis of courts’ judgments, the meaning of “reasonable time� when time at large occurs was determined. “Reasonable time� means reasonable under the existing circumstances, assuming that those circumstances, in so far as they involve delay, are not caused or attributed to by him and excluding circumstances which were under the control of the contractor, considering what in ordinary circumstances was a reasonable time for performance and then considering to what extent the time for performance of the contractor was in fact extended by extraordinary circumstances outside his control." @default.
- W87378054 created "2016-06-24" @default.
- W87378054 creator A5013984285 @default.
- W87378054 date "2007-06-01" @default.
- W87378054 modified "2023-09-24" @default.
- W87378054 title "Time at large and reasonable time for completion" @default.
- W87378054 cites W1551634254 @default.
- W87378054 cites W637927091 @default.
- W87378054 hasPublicationYear "2007" @default.
- W87378054 type Work @default.
- W87378054 sameAs 87378054 @default.
- W87378054 citedByCount "0" @default.
- W87378054 crossrefType "dissertation" @default.
- W87378054 hasAuthorship W87378054A5013984285 @default.
- W87378054 hasConcept C127413603 @default.
- W87378054 hasConcept C144133560 @default.
- W87378054 hasConcept C15744967 @default.
- W87378054 hasConcept C162118730 @default.
- W87378054 hasConcept C162324750 @default.
- W87378054 hasConcept C162853370 @default.
- W87378054 hasConcept C17744445 @default.
- W87378054 hasConcept C190253527 @default.
- W87378054 hasConcept C199539241 @default.
- W87378054 hasConcept C21547014 @default.
- W87378054 hasConcept C2778447849 @default.
- W87378054 hasConcept C2780141013 @default.
- W87378054 hasConcept C2780732561 @default.
- W87378054 hasConcept C2780876879 @default.
- W87378054 hasConcept C41008148 @default.
- W87378054 hasConcept C42475967 @default.
- W87378054 hasConcept C542102704 @default.
- W87378054 hasConcept C55451941 @default.
- W87378054 hasConceptScore W87378054C127413603 @default.
- W87378054 hasConceptScore W87378054C144133560 @default.
- W87378054 hasConceptScore W87378054C15744967 @default.
- W87378054 hasConceptScore W87378054C162118730 @default.
- W87378054 hasConceptScore W87378054C162324750 @default.
- W87378054 hasConceptScore W87378054C162853370 @default.
- W87378054 hasConceptScore W87378054C17744445 @default.
- W87378054 hasConceptScore W87378054C190253527 @default.
- W87378054 hasConceptScore W87378054C199539241 @default.
- W87378054 hasConceptScore W87378054C21547014 @default.
- W87378054 hasConceptScore W87378054C2778447849 @default.
- W87378054 hasConceptScore W87378054C2780141013 @default.
- W87378054 hasConceptScore W87378054C2780732561 @default.
- W87378054 hasConceptScore W87378054C2780876879 @default.
- W87378054 hasConceptScore W87378054C41008148 @default.
- W87378054 hasConceptScore W87378054C42475967 @default.
- W87378054 hasConceptScore W87378054C542102704 @default.
- W87378054 hasConceptScore W87378054C55451941 @default.
- W87378054 hasLocation W873780541 @default.
- W87378054 hasOpenAccess W87378054 @default.
- W87378054 hasPrimaryLocation W873780541 @default.
- W87378054 hasRelatedWork W124933571 @default.
- W87378054 hasRelatedWork W1443736580 @default.
- W87378054 hasRelatedWork W2074869257 @default.
- W87378054 hasRelatedWork W2201667277 @default.
- W87378054 hasRelatedWork W2267985919 @default.
- W87378054 hasRelatedWork W2418609379 @default.
- W87378054 hasRelatedWork W2475356991 @default.
- W87378054 hasRelatedWork W2494063361 @default.
- W87378054 hasRelatedWork W2503847717 @default.
- W87378054 hasRelatedWork W2553686211 @default.
- W87378054 hasRelatedWork W2557773977 @default.
- W87378054 hasRelatedWork W2907423905 @default.
- W87378054 hasRelatedWork W3132440388 @default.
- W87378054 hasRelatedWork W333278144 @default.
- W87378054 hasRelatedWork W560805239 @default.
- W87378054 hasRelatedWork W655666381 @default.
- W87378054 hasRelatedWork W656248362 @default.
- W87378054 hasRelatedWork W85092339 @default.
- W87378054 hasRelatedWork W1654587030 @default.
- W87378054 hasRelatedWork W2185394723 @default.
- W87378054 isParatext "false" @default.
- W87378054 isRetracted "false" @default.
- W87378054 magId "87378054" @default.
- W87378054 workType "dissertation" @default.